JBCC Contract Template fot Minor Works JBCC Minor Works Contract Doc. October 10, | Author: Sarisha Harrychund | Category: General Contractor. JBCC Minor Works Agreement. Edition: Year Published: March Author: The Joint Building Contracts Committee Publisher: The Joint Building. JBCC Minor Works Agreement Contract Data Edition: Year Published: Publisher: Joint Building Contracts Committee Price: R Incl.
|Published (Last):||18 September 2014|
|PDF File Size:||14.80 Mb|
|ePub File Size:||2.25 Mb|
|Price:||Free* [*Free Regsitration Required]|
JBCC: Joint Building Contracts Committee
The JBCC supplies printed documents exclusively to constituents and does not sell direct to users. The retention held shall include any unpaid amount due [ We are a non-profit group that run this website to share documents. Where such word or phrase is not highlighted it shall bear the meaning consistent with the context of its use. The form of guarantee provided by the employer or contractor, as stated in the contract data, from which a party may recover expense and loss in the event of default SITE: Such guarantee shall be issued by a guarantor to the reasonable approval of the employer 2.
If it is considered essential to make changes, users are advised that it is necessary for such changes to be drafted by qualified legal persons with extensive knowledge of the JBCC documentation and the construction industry. The other objectives of the JBCC are to: The employer may employ others [5.
The documentation sets out a clear, balanced and enforceable set of procedures, rights and obligations, which when competently managed and administered, protect the employer and contractor alike.
The bank rate that is applicable from time to time to registered banks when borrowing money from the Central or Reserve Bank of the country named in the contract data.
No representations, terms, conditions or warranties not contained in this agreement shall be binding on the parties. The ruling bank rate on the first calendar day of each month shall be used in calculating the interest due for such month JBCC: M inor W orks Agreement Page 16 The principal agent shall be informed of the name of such representative where so appointed.
The construction period and latent defects liability period shall commence with the handover of the site 5. The principal agent shall include such interest in the next payment certificate [ Unauthorised reproduction of the work is an infringement of the copyright in the work. Where the final account: Either party may, at any time, by notice to the other change, owrks physical address provided that it is in the same country as that initially monor in the contract data 1.
Where the final payment certificate favours the employer the security shall expire when the contractor makes payment No agreement or addendum varying, adding to, deleting or terminating this agreement including this clause shall be effective unless reduced to writing and signed by the parties Failure to agree the value shall not relieve the contractor of his responsibility to comply with the contract instruction The principal agent shall not preselect any of the alternatives available jbbcc the contractor Such contract minutes shall be issued to the employer and the contractor for action.
Please help us to share our service with your friends.
JBCC Minor Works Contract Doc – Free Download PDF
In pursuance of the objective the parties undertake to carry out their reciprocal obligations 1. Series documents are obtainable through most regional offices of JBCC constituents as listed on the cover of the document.
Thank you for interesting in our services.
No agreement jbvc addendum varying, adding to, deleting or terminating this agreement including this clause shall be effective unless reduced to writing and signed by the parties 1. The contractor shall state the choice of security in his contract data, failing which he shall be deemed to have selected retention [2.
The document drawn up jbcx to the measuring system as stated in the contract data. Persons entering into or preparing contracts using the JBCC Minor Works Agreement are warned of the dangers inherent in modifying any part thereof. The word or phrase of a definition is highlighted in the text and shall bear the meaning assigned to it in this 1.
Please copy and paste this embed script to where you want to embed Embed Script. Such liability shall not exceed the insurance deductible stated in the contract data in any woks instance 4.
The contractor may appoint a competent nbcc to administer and control the works in his stead. Experience has shown that changes drafted by others, including members of the building professions, often have results very different from those intended which may be prejudicial to either or both parties Special Woris Although this Minor Works Agreement is part of the JBCC Series documents it has been formulated for use specifically with its own supplementary documents.
JBCC Minor Works Contract Doc
The land or place on, over, under, in or through which the works is to be executed and as stated in the contract data TAX: A defect that a reasonable inspection of the works by the principal agent would not have revealed before the issue of the defects list LAW: The contractor shall be entitled to additional payment due to a delay caused by: Size px x x x x We need your help to maintenance this website.
The edition of the Summary Procedure Rules for the Conduct of Arbitrations, published ibcc the Association of Arbitrators Southern Africa and current when the dispute is declared, shall apply The contractor is a jbfc to medium enterprise The employer carries the major liabilities related to the works The employer is responsible for the primary insurances related to the works This agreement wotks not designed or intended for use where the works: Where applicable the principal agent shall treat such correction as an adjustment [ No part of this publication may be reproduced, stored in any retrieval system, or transmitted, in any form or by any means, electronic, mechanical, photocopying, scanning, recording, woeks otherwise, without the prior permission of the Joint Building Contracts Committee.
Such change shall be deemed to be a contract instruction 7. The wotks shall report the cause and effect of such delay and the working days claimed to the principal agent at the next meeting held [6. The principal agent shall hold a signed set of contract documents to be produced as and when required 4. The amount payable by the contractor [ The contract minutes shall be tabled for approval at the following meeting 6. The parties shall give all notices worms pay all charges required by such authorities.
Mnior done and signed at on Name of signatory Capacity of signatory for and on behalf of the employer who by signature hereof warrants authorisation hereto Signed as Witness 1 Thus kbcc and signed at Name of signatory on for and on behalf of the contractor who by signature hereof warrants authorisation hereto Capacity of signatory Signed as Witness 2 Details of Witness 1 Details of Witness 2 Name: The contractor may dispute such reasons and the effects thereof [ Where applicable such amount shall M inor W orks Agreement Page 4 include existing buildings and their contents.
Should the contractor fail to submit such an analysis the principal agent shall prepare the analysis